MA1009-CS110720
(8/5/2011) Keith Marvin - RE: proposalsPage 1
From:
"Mark Holliday" <mholliday@tnp-online.com>
To:
"Keith Marvin" <kmarvin@coppelltx.gov>
Date:
7/20/2011 2:28 PM
Subject:
RE: proposals
Attachments:
coppell standard contract - alex canal.doc
Keith,
Attached is the combined word document with revisions we discussed.
Thanks for the opportunity to be of service.
Mark
-----Original Message-----
From: Keith Marvin [mailto:kmarvin@coppelltx.gov]
Sent: Tuesday, July 19, 2011 4:37 PM
To: Mark Holliday
Subject: Re: proposals
Here you go.
Keith Marvin, P.E.
Project Engineer
(972) 304-3681
>>> "Mark Holliday" <mholliday@tnp-online.com> 7/18/2011 6:29 PM >>>
Keith,
Just wanted to check in with you about the proposals I sent for Alex
Canal and the CAD services. Let me know if you have any questions or
direction on how to proceed.
Thanks.
Mark
CITY OF COPPELL
CONSULTING ENGINEERS CONTRACT
STATE OF TEXAS §
KNOW ALL BY THESE PRESENTS §
CITY OF COPPELL §
THIS ENGINEERING SERVICES CONTRACT,
hereinafter referred to as
"Contract," made, entered into and executed this the _______day of ______________, 2011, by
and between the City of Coppell acting by and through the City Manager with approval of the City
Council hereinafter referred to as "City", and Teague, Nall and Perkins, Inc., hereinafter referred
to as "Engineer".
WITNESSETH
WHEREAS, the City desires to contract for Professional Engineering Services, hereinafter
referred to as "Services", in connection with the Alex Drive Canal Rehabilitation, hereinafter
referred to as the "Project"; and
WHEREAS, the Engineer is acceptable to the City and is willing to enter into a Contract
with the City to perform the hereinafter defined Services necessary to complete the Project; and
WHEREAS, said Services shall be as defined herein and in the detailed Scope of Services,
Attachment A, incorporated herein by attachment and by reference; and
WHEREAS, this contract shall be administered on behalf of the City by its City Engineer
or his duly authorized representative. The Engineer shall fully comply with any and all
instructions from said City Engineer.
AGREEMENT
NOW, THEREFORE, the City and the Engineer, in consideration of the mutual covenants
and agreements herein contained, do mutually agree as follows:
The City agrees to retain the Engineer, and the Engineer agrees to provide Services in connection
with the Project as defined herein, and for having rendered such Services the City agrees to pay to
the Engineer fee for these Services as mutually agreed. All Services under this Contract shall be
performed under the direct supervision of the City Engineer.
1. Scope of Services,
A. Basic Services Parts I & II: The work tasks and activities to be performed and
deliverable to be provided by the Engineer shall be in accordance with Attachment
A, Scope of Services, including modifications to the Basic Services as mutually
agreed to by the City and the Engineer in accordance with the provisions of this
Contract.
B. Additional Services Not Included In Basic Services: When mutually agreed to in
writing by the City and the Engineer, the Additional Services shall be provided by
the Engineer. These Additional Services are not included as a part of Basic
Services and shall be paid for by the City in addition to payment for Basic Services.
Should it be determined that one or more of the requirements of this Contract
conflict with the requirements of the Scope of Services, including modifications to
the Scope of Services or any attachments to this contract; the requirement of the
Contract shall govern.
2. Progress Schedule. Within ten (10) days after receiving Notice to Proceed (NTP) the
Engineer shall submit to the City a Schedule of Services consisting of a listing of the major
Project tasks, the estimated consultant hours required to perform the tasks, the percentage of
the Contract budget estimated to be allocated to each task and a bar chart schedule showing
task beginning and completion dates. Significant milestones for the Project shall be
identified. At a minimum, milestones shall be provided for the three design submittals
described in Attachment A, Scope of Services: Conceptual Design Submittal, Preliminary
Design Submittal, and Final Plans, Specifications, and Estimate (PS&E) Submittal. Based
on Schedule of Services, the City shall compile Attachment D, Project Schedule which
shall become a part of this Contract upon approval of the Engineer and the City. The
Engineer shall provide to the City information to report and monitor the design tasks
within the Project Schedule by completing a "Design Progress Report" on a form provided
by the City. The Engineer shall complete and provide to the City said report at two week
intervals.
Page 2
3. Compensation.
A. Basic Services Part I Fee: The Engineer shall be paid a fee for Basic Services Part
I under this Contract pursuant to the Fee Schedule described in Attachment A,
Scope of Services. Basic Services Part I Fee shall not exceed the lump sum of
Sixty Six Thousand Five Hundred dollars ($66,500) provided, however,
that modifications to the Basic Services Part I, or other conditions defined herein
may necessitate a change of Fee which shall be reduced to writing and approved by
the City or its designee.
B. Basic Services Part II Fee: The Engineer should be paid a fee under this Contract
for Basic Services Part II pursuant to the Fee Schedule described in Attachment A,
Scope of Services. Basic Services Part II Fee shall not exceed the lump sum of
Twelve Thousand dollars ($12,000) provided, however, that modifications to the
Basic Services Part II, or other conditions defined herein may necessitate a change
of Basic Fee which shall be reduced to writing and approved by the City or its
designee.
C. Total Maximum Fee: Total Maximum Fee for this Contract shall be a lump sum of
Seventy Eight Thousand Five Hundred dollars ($78,500): The lump sum Basic
Services Part I Fee plus the lump sum Basic Services Part II Fee.
D. Invoices: The Engineer shall submit invoices at not less than thirty (30) calendar
days for Basic Services Part I and/or Basic Services Part II on or before the twenty
fifth (25th) calendar day of the month, or the preceding business day if the twenty
fifth occurs on a weekend and/or observed holiday. Payment shall be based on the
invoices submitted to the City, provided that Services completed as indicated in the
Design Progress Reports approved by the City equals or exceeds the increment
percentage requested on the Engineer's invoices. Engineer's invoices to City shall
provide complete information and documentation to substantiate Engineer's charges
and shall be in a form to be specified by the City Engineer. Should additional
documentation be requested by the City Engineer the Engineer shall comply
promptly with such request.
E. Payments: All payments to Engineer shall be made on the basis of the invoices
submitted by the Engineer and approved by the City. Following approval of
invoices, City shall endeavor to pay Engineer promptly, however, under no
circumstances shall Engineer be entitled to receive interest on amounts due. The
City, in compliance with Texas State law, shall process a maximum of one payment
to the Engineer per month. City reserves the right to correct any error that may be
Page 3
discovered in any invoice whether paid to the Engineer or not, and to withhold the
funds requested by the Engineer relative to the error.
4. Fee Increases. Any other provision in this Contract notwithstanding, it is specifically
understood and agreed that the Engineer shall not be authorized to undertake any Services
pursuant to this Contract requiring the payment of any fee, expense or reimbursement in
addition to the fees stipulated in Article 3 of this Contract, without having first obtained
specific written authorization from the City. The written authorization for additional
Services shall be in the form of a Modification to the Scope of Services approved by the
City Engineer and/or the City Council, if required.
5. Modifications to the Scope of Services. Either the Engineer or the City Engineer may
initiate a written request for a Modification to the Scope of Services when in the opinion of
the requesting Party, the needs and conditions of the Project warrant a modification. Upon
the receipt of a request by either Party, the Engineer and the City Engineer shall review
the conditions associated with the request and determine the necessity of a modification.
When the Parties agree that a modification is warranted, the Engineer and the City
Engineer shall negotiate the specific modification(s) and any changes in the Total
Maximum Fee or Project Schedule resulting from the modification(s). Approval of a
modification shall be in the form of a written Modification to the Scope of Services which
clearly defines the changes to the previously approved Scope of Services, Fee and/or
Project Schedule. Said written Modification shall be approved by Engineer, authorized by
the City Council, if required, and issued by the City Engineer. Issuance of the approved
Scope of Services modification shall constitute a notice to proceed with the Project in
accordance with the modified Scope of Services. The City Engineer may issue written
Modifications to the Scope of Services without prior approval of the City Council when the
modifications are to be accomplished within the authorized Total Maximum Fee and do not
materially or substantively alter the overall scope of the Project, the Project Schedule or the
Services provided by the Engineer.
6. Project Deliverables. For each submittal identified in Attachment A, Scope of Services,
the Engineer shall provide the City with one set of reproducibles, one set of bluelines or
hard copy and electronic media of the submittal documents. For any required
environmental assessment, the Engineer shall provide one set of draft and one set of final
Environmental Reports. The Environmental Reports shall be submitted as original
reproducibles and on electronic media. The electronic file may omit photographs and
government prepared maps. If photographs are included in the report they shall be taken
with a 35 mm camera or larger format camera. Color laser copies may be substituted for
the original photographs in the final report.
Page 4
A transmittal letter shall be included with the Environmental Reports and shall include an
executive summary outlining: a.) Findings of the Reports; b.) Conclusions; c.)
Recommendations; and d.) Mitigation/remediation cost estimates.
7. Project Control. It is understood and agreed that all Services shall be performed under the
administrative direction of the City Engineer. No Services shall be performed under this
Contract until a written Notice to Proceed is issued to the Engineer by the City Engineer.
In addition, the Engineer shall not proceed with any Services after the completion and
delivery to the City of the Conceptual Design Submittal, Preliminary Design Submittal, or
the Final PS&E Submittal as described in the Basic Services without written instruction
from the City. The Engineer shall not be compensated for any Services performed after
the said submittals and before receipt of City's written instruction to proceed.
8. Partnering. The City shall encourage participation in a partnering process that involves the
City, Engineer and his or her sub-consultants, and other supporting jurisdictions and/or
agencies. This partnering relationship shall begin at the Pre-Design Meeting and continue
for the duration of this Contract. By engaging in partnering, the parties do not intend to
create a legal partnership, to create additional contractual relationships, or to in any way
alter the legal relationship which otherwise exists between the City and the Engineer. The
partnering effort shall be structured to draw on the strengths of each organization to identify
and achieve reciprocal goals. The objectives of partnering are effective and efficient
contract performance and completion of the Project within budget, on schedule, in
accordance with the Scope of Services, and without litigation. Participation in partnering
shall be totally voluntary and all participants shall have equal status.
9. Disputes. The City Engineer shall act as referee in all disputes under the terms of this
Contract between the Parties hereto. In the event the City Engineer and the Engineer are
unable to reach acceptable resolution of disputes concerning the Scope of Services to be
performed under this Contract, the City and the Engineer shall negotiate in good faith
toward resolving such disputes. The City Engineer may present unresolved disputes
arising under the terms of this Contract to the City Manager or designee. The decision of
the City Manager or designee shall be final and binding. An irreconcilable or unresolved
dispute shall be considered a violation or breach of contract terms by the Engineer and shall
be grounds for termination. Any increased cost incurred by the City arising from such
termination shall be paid by the Engineer.
10. Engineer's Seal. The Engineer shall place his Texas Professional Engineers seal on all
engineering documents and engineering data prepared under the supervision of the
Engineer in the performance of this Contract.
11. Liability. Approval of the Plans, Specifications, and Estimate (PS&E) by the City shall
not constitute nor be deemed a release of the responsibility and liability of Engineer, its
Page 5
employees, subcontractors, agents and consultants for the accuracy and competency of their
designs, working drawings, tracings, magnetic media and/or computer disks, estimates,
specifications, investigations, studies or other documents and work; nor shall such approval
be deemed to be an assumption of such responsibility by the City for any defect, error or
omission in the design, working drawings, tracings, magnetic media and/or computer disks,
estimates specifications, investigations, studies or other documents prepared by Engineer,
its employees, subcontractors, agents and consultants. Engineer shall indemnify City for
damages resulting from such defects, errors or omissions and shall secure, pay for and
maintain in force during the term of this Contract sufficient errors and omissions insurance
in the amount of $250,000.00 single limit, with certificates evidencing such coverage to be
provided to the City. The redesign of any defective work shall be the sole responsibility
and expense of the Engineer. Any work constructed, found to be in error because of the
Engineer's design, shall be removed, replaced, corrected or otherwise resolved at the sole
responsibility and expense of the Engineer. The parties further agree that this liability
provision shall meet the requirements of the express negligence rule adopted by the Texas
Supreme Court and hereby specifically agree that this provision is conspicuous.
12. Indemnification. Engineer shall indemnify, hold harmless and defend the City of
Coppell, its officers, agents and employees from any loss, damage, liability or expense,
including attorney fees, on account of damage to property and injuries, including death, to
all persons, including employees of Engineer or any associate consultant, which may arise
from any errors, omissions or negligent act on the part of Engineer, its employees, agents,
consultants or subcontractors, in performance of this Contract, or any breach of any
obligation under this Contract. It is further understood that it is not the intention of the
parties hereto to create liability for the benefit of third parties, but that this agreement shall
be solely for the benefit of the parties hereto and shall not create or grant any rights,
contractual or otherwise to any person or entity. The parties further agree that this
indemnification provision shall meet the requirements of the express negligence rule
adopted by the Texas Supreme Court and hereby specifically agree that this provision is
conspicuous.
13. Delays and Failure to Perform. Engineer understands and agrees that time is of the
essence and that any failure of the Engineer to complete the Services of this Contract within
the agreed Project Schedule shall constitute material breach of this Contract. The Engineer
shall be fully responsible for its delays or for failures to use diligent effort in accordance
with the terms of this Contract. Where damage is caused to the City due to the Engineer's
failure to perform in these circumstances, the City may withhold, to the extent of such
damage, Engineer's payments hereunder without waiver of any of City's additional legal
rights or remedies. The Engineer shall not be responsible for delays associated with
review periods by the City in excess of the agreed Project Schedule.
14. Termination of Contract. It is agreed that the City or the Engineer may cancel or
terminate this Contract for convenience upon fifteen (15) days written notice to the other.
Page 6
Immediately upon receipt of notice of such cancellation from either party to the other, all
Services being performed under this Contract shall immediately cease. Pending final
determination at the end of such fifteen-day period, the Engineer shall be compensated on
the basis of the percentage of Services provided prior to the receipt of notice of such
termination and indicated in the final Design Progress Report submitted by the Engineer
and approved by the City.
15. Personnel Qualifications. Engineer warrants to the City that all Services provided by
Engineer in the performance of this Contract shall be provided by personnel who are
appropriately licensed or certified as required by law, and who are competent and qualified
in their respective trades or professions.
16. Quality Control. The Engineer agrees to maintain written quality control procedures.
The Engineer further agrees to follow those procedures to the extent that, in the Engineer's
judgment, the procedures are appropriate under the circumstances.
17. Ownership. All Engineer's designs and work product under this Contract, including but
not limited to tracings, drawings, electronic or magnetic media and/or computer disks,
estimates, specifications, investigations, studies and other documents, completed or partially
completed, shall be the property of the City to be used as City desires, without restriction;
and Engineer specifically waives and releases any proprietary rights or ownership claims
therein and is relieved of liability connected with any future use by City. Copies may be
retained by Engineer. Engineer shall be liable to City for any loss or damage to such
documents while they are in the possession of or while being worked upon by the Engineer
or anyone connected with the Engineer, including agents, employees, consultants or
subcontractors. All documents so lost or damaged while they are in the possession of or
while being worked upon by the Engineer shall be replaced or restored by Engineer
without cost to the City.
18. Project Records and Right to Audit. The Engineer shall keep, retain and safeguard all
records relating to this Contract or work performed hereunder for a minimum period of
three (3) years following the Project completion, with full access allowed to authorized
representatives of the City upon request for purposes of evaluating compliance with
provisions of this Contract. Should the City Engineer determine it necessary, Engineer
shall make all its records and books related to this Contract available to City for inspection
and auditing purposes.
19. Non-Discrimination. As a condition of this Contract, the Engineer shall take all necessary
action to ensure that, in connection with any work under this Contract it shall not
discriminate in the treatment or employment of any individual or groups of individuals on
the grounds of race, color, religion, national origin, age, sex or physical impairment
unrelated to experience, qualifications or job performance, either directly, indirectly or
through contractual or other arrangements.
Page 7
20. Gratuities. City of Coppell policy mandates that employees shall never, under any
circumstances, seek or accept, directly or indirectly from any individual doing or seeking to
do business with the City of Coppell, loans, services, payments, entertainment, trips,
money in any amount, or gifts of any kind.
21. No Waiver. No action or failure to act on the part of either Party at any time to exercise
any rights or remedies pursuant to this Contract shall be a waiver on the part of that Party
of any of its rights or remedies at law or contract.
22. Compliance with Laws. The Engineer shall comply with all Federal, State and local
laws, statutes, City Ordinances, rules and regulations, and the orders and decrees of any
courts, or administrative bodies or tribunal in any matter affecting the performance of this
Contract, including without limitation, worker's compensation laws, minimum and
maximum salary and wage statutes and regulations, and licensing laws and regulations.
When required, Engineer shall furnish the City with satisfactory proof of compliance
therewith.
23. Severability. In case one or more of the provisions contained in this Contract shall for any
reason be held invalid, illegal, or unenforceable in any respect, such invalidity, illegality or
unenforceability shall not affect any other provisions hereof and this Contract shall be
construed as if such invalid, illegal or unenforceable provision had never been contained
herein.
24. Venue. With respect to any and all litigation or claims, the laws of the State of Texas shall
apply and venue shall reside in Dallas County.
25. Prior Negotiations. This Contract supersedes any and all prior understandings and
agreement by and between the Parties with respect to the terms of this Contract and the
negotiations preceding execution of this Contract.
26. Contacts. The Engineer shall direct all inquiries from any third party regarding
information relating to this Contract to the City Engineer.
Page 8
27. Notification. All notices to either Party by the other required under this Contract shall be
delivered personally or sent by certified U.S. mail, postage prepaid, addressed to such Party
at the following respective addresses:
City: City of Coppell, Texas
Kenneth M. Griffin, P.E.__
City Engineer___________
255 Parkway Blvd._______
Coppell, TX 75019______
Engineer: Mark J. Holliday, P.E. ____
Teague, Nall and Perkins, Inc.
12160 North Abrams Road, Suite 508
______
Dallas, Texas 75243
IN WITNESS WHEREOF, the City of Coppell, Texas and the Engineer has caused these
presents to be executed by duly authorized representatives on the day and year set forth above.
THE CITY OF COPPELL ENGINEER:___________________
BY: BY:
______________________ ______________________________
City Manager Name & Title
Date: __________________ Date:_________________________
ATTEST: ATTEST:
_______________________ ______________________________
(CORPORATE SEAL)
Page 9
ATTACHMENT ‘A’
SCOPE OF SERVICES
Engineer
The agrees to render services necessary for the development and completion of the
Project as outlined herein.
Over the last several years, the canal between Enclaves Court and Alex Drive has experienced
slope failure and retaining wall failure along the east bank. The City evaluated various
construction options in the past, but a feasible solution was never finalized. The west bank is
owned by a neighborhood HOA, and minor slope failures and wall movement along the west
bank can be observed. The east bank of the canal is owned by the City, and a recent wall
failure near Parkway Boulevard has increased the awareness of the need to address the
issue. The Basic Services to be performed under this Contract include the following scope of
work:
1. Project limits consist of the east bank of the canal from Parkway Blvd to
approximately 700 linear feet south to the 90-degree bend in the canal, and tie into
the existing headwall at this location.
2. Evaluate up to four options for construction techniques and materials for
reconstructing the wall and stabilizing the east slope.
3. Prepare USACE Pre-Construction Notification for Nationwide Permit 13 - Bank
Stabilization if necessary.
4. Prepare hydraulic model to verify no adverse impact of wall improvements on peak
water surface elevations.
5. Provide to the City a summary of evaluated options w/ cost opinions and
recommendations.
6. Attend one neighborhood meeting with City staff to discuss alternatives with adjacent
residents.
7. Prepare construction drawings and specifications for up to two options to allow
alternate methods to be bid by contractors.
8. Provide construction administration services and structural inspection of walls.
Page 10
BASIC SERVICES PART I:
CityEngineer
1. When requested by the , the shall attend preliminary conferences with
City
authorized representatives of the regarding the project and such other conferences as
City
may be necessary in the opinion of the so that the plans and specifications which are
Engineer,
to be developed hereunder by the will result in providing facilities which are
City
economical in design and conform to instruction from the .
Engineer
2. The shall attend such conferences with officials of other agencies including other
City
engineering and/or surveying firms under contract with the , as may be necessary in
City Engineer’s
the opinion of the for coordination with the other agencies. It shall be the
duty hereunder to secure necessary information from such agencies.
Engineer
3. The shall utilize previously completed geotechnical report provided by City.
City
Engineer shall advise the if any additional subcontract work that is not already
included in this contract becomes necessary to the design of the project. Such additional
subcontracted work, tests, surveys, or subsurface investigations shall be made only upon
City
authorization by and at the expense of the .
Engineer
4. The shall provide necessary design field surveys for his use in the preparation of
preliminary and final plans and specifications.
Survey For Design: Provide detailed topographic survey for project along the project
corridor. This will include horizontal and vertical location of existing above ground features
and visible utility appurtenances throughout the length of the project corridor including, but
not limited to, existing pavement connections, sidewalks, trees, fences, water valves, fire
hydrants and manholes. Flowlines of existing culvert and storm drain outfalls will be shot
and elevations provided. Survey limits will be from east fenceline to west fenceline, and
extend from Parkway Blvd to the 90-degree bend located approximately 700 LF south.
(a) Establish control network utilizing GPS and City of Coppell published datum.
Unless otherwise required, horizontal datum will be NAD 83 and NAVD 88 for
vertical datum.
(b) Perform field surveys to tie the horizontal and vertical locations of franchise
utilities when located close to proposed facilities.
(c) Establish vertical control benchmarks within the project limits on existing
permanent structures.
(d) Tie benchmarks to as-built plans for correlation of datum.
Page 11
A. PRELIMINARY DESIGN
After studying up to four design concepts in sufficient detail to evaluate conceptual cost
opinions and constructability concerns, the Engineer will provide a brief summary of options
with recommendations to the City. City shall select a base design and one alternate design for
Engineer to prepare construction plans to be used for contractor bidding.
Engineer shall prepare a HEC-RAS hydraulic model for existing conditions and proposed
conditions between the limits of existing concrete spillway downstream of Parkway Blvd. to the
upstream end of the project. Effective FEMA hydrology shall be used for model, and does not
include FEMA map changes or detailed drainage reports.
Engineer
1. The shall then proceed with preparation of the preliminary design of the project
CityCity
incorporating all comments received from the and agreed upon by both the and
Engineer
the into these plans. Project design shall be in accordance with environmental
standards provided by the City, as well as known state and federal guidelines applicable to
the project.
a. Prepare typical proposed wall cross sections.
b. Establish preliminary horizontal alignment for wall.
c. Establish preliminary vertical profiles for wall.
d. Show major features on plan sheets including edges of roadway, fences,
sidewalks, trees, and culverts.
e. Show existing storm system improvements.
f. Show known utility crossings and nearby adjacent utilities, and other topographic
features as identified from field surveys and information provided by utility
companies and the City’s record drawings.
Engineer
g. The shall supply the preliminary plans to all known utility companies,
including franchised utilities and pipeline companies which have known existing
facilities within the limits of the Project. One set of dated preliminary plans, and
one set of dated and approved advertising (final) plans shall also be submitted at
the appropriate intervals.
Engineer
h. The shall provide detailed design data, profiles, cross-sections where
appropriate, opinions of probable cost, and furnish two (2) copies of detailed
City
preliminary design plans for the project to the for review.
2. Prepare exhibit of design alternatives for a public meeting. Engineer shall attend one
neighborhood meeting with City staff to discuss alternatives with adjacent residents.
Page 12
CityEngineer
3. After receipt of preliminary design review comments from the , the shall
make all corrections noted and then commence preparation of the final design plans and
specification/contract documents.
Page 13
C. FINAL PLANS, SPECIFICATIONS, AND ESTIMATE (P S & E)
CityEngineer
1. Incorporating all review comments from the preliminary design submittal, the
will complete the final plans, prepare contract documents/specifications, and a final opinion
of probable cost for the authorized construction units. This shall include summaries of bid
Engineer
items and quantities, but the does not guarantee that Contractor bids will not
City
vary from such opinion. Each of these items (2 copies each) shall be submitted to the
for final approval.
a. Develop miscellaneous sheets such as Title Sheet, Horizontal Control Sheet, General
Notes & Quantities, and Standard Details.
b. Prepare Erosion Control Plan sheets (full size, 1:40 scale) for proposed improvements.
The successful bidder (contractor) will be required to supply and submit a formal
SWPPP to the TCEQ as owner and operator of the construction project.
c. Prepare traffic control and construction phasing plan for proposed improvements.
d. Provide typical retaining wall design cross sections.
e. Incorporate comments from the utility companies pertaining to the location of existing
facilities and organize a utility coordination meeting among all impacted utilities at City
Hall.
f. Finalize Special Conditions, which will include Special Technical specifications.
g. Meet with City to develop final phasing of construction. City will notify the City of
Coppell Police and Fire Departments of all proposed construction phase traffic.
h. Complete quantity take-off and prepare final estimate of probable construction cost
based on final plans.
i. Prepare final bid documents including bid proposal forms, construction plans,
specifications, and contract documents.
2. After receipt of final plan/specifications/contract documents review comments from the
CityEngineer
, the shall make all corrections noted and then provide up to twelve (12)
copies of contract documents and final bid plans to Contractors bidding the Project.
Contract documents shall contain the Notice to Bidders, Proposal, Wage Rates, General
and Special Provisions, Special Specifications, Insurance Statement, Payment,
City
Performance, and Maintenance Bonds, and all other required Contract forms.
3. The original drawings of all plans shall be plotted in ink on approved plastic film sheets, or
City EngineerCity
as otherwise approved by the , and shall become the property of the .
CityEngineer
may use such drawings in any manner it desires provided, however, that the
shall not be liable for the use of such drawings for any project other than the project
described herein.
Page 14
D. CONSTRUCTION ADMINISTRATION
.
EngineerCity
1. The will assist the in the advertisement for bids--prepare Notice to Bidders
for required newspaper advertising --and place notice with Texas Contractor magazine and
Dodge Report.
Engineer City.
2. The will attend a pre-bid meeting if deemed necessary by the
Engineer
3. The shall assist in the tabulation and review of all bids received for the
City
construction of the improvements, and shall make recommendations to the concerning
Engineer
these bids. At any time during the construction of this project, the shall advise
on special review shop drawings required of the Contractor by the Construction
Contract(s). Such review shall be for general conformance with the design concept and
general compliance with the plans and specifications under the Construction Contract(s).
CityEngineer
4. After selection of Contractor(s) and award of contract(s) by the , the will
assist in the preparation of contract documents, including contract, performance, payment,
City
and maintenance bonds and all other related forms required to initiate construction on
the project(s).
EngineerCity
5. will attend a pre-construction conference with staff, Contractor(s), and all
affected utility companies.
Engineer
6. will provide periodic field representation and will monitor construction progress as
Engineer
deems necessary, including possible scheduled meetings with the project
Engineer
inspector and the Contractor(s) to discuss the construction progress. will provide
required structural inspection when notified at the appropriate time. It is estimated that up
City
to four site visits will be made. A written status can be provided to the after each of
these meetings if needed.
EngineerCity
7. will consult and advise the regarding the need for any contract change
City
orders and will prepare change orders as required for approval.
Engineer
8. will be available for interpretation of plans and specifications as may be required
by the Contractor(s) in the field.
EngineerCity Inspector
9. The will, with assistance from the on the project(s), prepare and
City.
process monthly and final pay requests from the Contractor(s) to the
EngineerCity
10. will provide, in conjunction with the , a final inspection of the project and
provide a “punch list” of deficient items to the Contractor(s).
Engineer
11. will revise construction drawings as necessary to adequately reflect any revisions
in the construction from that which was represented on the plans and/or specifications.
Page 15
Engineer City
12. will provide the with one (1) set of mylar reproducible “Record Drawings”
within 30 days after the completion of the project including updated digital CAD files of the
City’s
new construction for use in the computerized mapping system.
Page 16
BASIC SERVICES PART II: Environmental Services
1. Section 404 Permit Assessment -
TNP will utilize Integrated Environmental Solutions, Inc. (IES) to provide professional
services regarding Section 404 permitting strategies. The permitting strategy will focus on
utilizing Nationwide Permit (NWP) 13 – Bank Stabilization for the proposed project and
identify ways to avoid or minimize impacts so that there will not be any preconstruction
notification to the USACE. If the project meets all terms and conditions of NWP 13, without
requiring notification under General Condition 27, IES will prepare a brief letter report
presenting the delineation, describing the project and how it meets all conditions of NWP
13.
2. Pre-Construction Notification under Nationwide Permit 13 -
If the proposed impacts exceed the allowed thresholds, a notification to the USACE is
required prior to construction of the proposed project. IES would detail the ecological
functions and values of the waters of the United States on the property, based on current
conditions and other previous documentation. Once these baseline conditions are
accepted by the USACE, these will be the functions and values that will be mitigated.
Although this project may only have minor impacts, the NWP submittal must detail the
planning process and provide compensatory mitigation for unavoidable impacts if
necessary. All tasks will be assembled into the Section 404 permit submittal to the USACE.
After the permit is submitted to the USACE, additional coordination may be required to
finalize the requirements of the permitting process.
Page 17
F. EXCLUSIONS
1. Providing a full-time on-site representative during construction.
2. Environmental assessments or USACE permitting beyond that described.
3. Fees for FEMA submittals, permits or advertising.
4. Certification that work is in accordance with plans and specifications, beyond standard
preparation of record drawings described.
5. Environmental cleanup.
6. Floodplain studies, map revisions, or detailed drainage reports.
7. Trench safety designs.
8. Quality control and testing services during construction.
9. Services in connection with condemnation hearings.
10. Design of underground storm drain infrastructure system improvements.
11. Design of water and sanitary sewer lines.
12. Preparation of drainage area map and drainage calculations.
13. On-site safety precautions, programs and responsibility.
14. Consulting services by others not included in proposal.
15. Traffic engineering report or study.
16. Title searches, boundary surveys, or property surveys.
17. Preparation of landscape plans or tree mitigation plans.
Page 18
COMPENSATION
:
The maximum overall fee established herein shall not be exceeded without written
authorization from the City of Coppell, justified by increased scope of services.
The following is a summary of the estimated charges for the various elements of the proposed
services:
Basic Services Part I Fee:
A. Engineering ..........................................................................................$ 55,500
B. Design Survey .....................................................................................$ 11,000
Subtotal: $ 66,500
Basic Services Part II Fee:.............................................................................Additional Services
A. Reimbursable Expenses (printing, as-built prep, etc) ……..………… $ 2,000
B. Environmental Services……………………………………………… $ 10,000
Subtotal: $ 12,000
Total Contracted Fee: $ 78,500
Page 19
TEAGUE NALL AND PERKINS, INC.
Standard Rate Schedule for Reimbursable/Multiplier Contracts
Effective January 1, 2011 to December 31, 2011*
Engineering / Technical From - To
Principal $150 - $230 Per Hour
Project Manager $120 - $200 Per Hour
Senior Engineer $110 - $210 Per Hour
Engineer $85 - $140 Per Hour
Landscape Architect / Planner $110 - $170 Per Hour
Landscape Designer $70 - $110 Per Hour
Designer $85 - $120 Per Hour
Senior Designer $100 - $150 Per Hour
CAD Technician $60 - $90 Per Hour
Senior CAD Technician $75 - $110 Per Hour
IT Consultant $120 - $150 Per Hour
IT Technician $85 - $120 Per Hour
Clerical $50 - $80 Per Hour
Resident Project Representative $70 - $120 Per Hour
Surveying
Survey Office Manager $130 - $180
Registered Professional Land Surveyor $120 - $150
S.I.T. $70 - $100
Senior Survey/SUE Technician $70 - $100
Junior Survey/SUE Technician $50 - $80
2-Person Field Crew w/Equipment $115
3-Person Field Crew w/Equipment $125
4-Person Field Crew w/Equipment $150
1-Person G.P.S. Crew w/Equipment $125
2-Person G.P.S. Crew w/Equipment $145
3-Person G.P.S. Crew w/Equipment $165
1-Person Robotic Crew w/Equipment $110
2-Person Robotic Crew w/Equipment $130
SUE QL-A Test Hole (0 – 4 ft)* $750 Per Hole
SUE QL-A Test Hole (4.1 - 8 ft)* $900 Per Hole
SUE QL-A Test Hole (8.1 – 12 ft)* $1,150 Per Hole
SUE QL-A Test Hole (12.1 – 20 ft)* $1,500 Per Hole
VAC Truck $250 Per Hour
Direct Cost Reimbursables
Photocopies, Scans & PDF Files: $0.10/page letter and legal size bond paper, B&W
$0.20/page 11” x 17” size bond paper, B&W
$1.00/page letter, legal and 11” x 17” color bond paper,
$2.00/page 22” x 34” and larger bond or vellum, B&W
$4.00/page 22” x 34” and larger bond or vellum, color
Plots: $1.00/page 11” x 17” size bond paper, B&W
$2.00/page 11” x 17” size bond paper, color
$4.00/page 22”x34” and larger bond or vellum, B&W
$6.00/page 22”x34” and larger paper or vellum, color
$6.00/page 22”x34” and larger mylar or acetate, B&W
Mileage $0.50/mile
Page 20